Terms of Service

[et_pb_section bb_built=”1″ fullwidth=”on” specialty=”off” next_background_color=”#000000″ _builder_version=”3.1.1″ custom_margin=”||0px|” custom_padding=”||0px|”][et_pb_fullwidth_header _builder_version=”3.1.1″ title=”Terms of Service” custom_margin=”35px||0px|” custom_padding=”0px||0px|” /][/et_pb_section][et_pb_section bb_built=”1″ prev_background_color=”#000000″ _builder_version=”3.1.1″ custom_margin=”0px|||” custom_padding=”0px|||” next_background_color=”#000000″][et_pb_row][et_pb_column type=”4_4″][et_pb_text _builder_version=”3.1.1″]

INSPECTION

All items are thoroughly inspected prior to shipment. Title passes to consignee at time shipment leaves the dock and carrier is agent of consignee.

DAMAGED GOODS

Do not accept any items delivered by the carrier unless they are in perfect condition. In the case of any damage the carrier’s agent must make the proper notation on the delivery receipt. Do not sign until this is done. THE CONSIGNEE MUST MAKE APPLICATION DIRECTLY TO THE CARRIER FOR ADJUSTMENT FOR ANY DAMAGED GOODS, CONCEALED OR OTHERWISE.

Lightning Lockers shall not be liable for loss or damage in transit.

WARRANTY

Lightning Lockers shall warrant their locker for the life of the product. Warranty shall include all defects in material and workmanship, excluding finish, vandalism, and improper installation.

Warranty covers original owner and is non-transferable.

Any goods found to be defective, upon examination by us, within 12 months from date of shipment, shall be repaired or replaced by us without charge, FOB factory within the continental United States. All export taxes, fees and duties occurring from warranty shipments beyond the continental United State will be the customer’s responsibility.

This warranty shall be null and void and of no effect unless we are notified of such defect, all within 12 months from date of shipment. Such notification shall be directed to the office of Lightning Lockers. No goods shall be returned without prior written approval.

Explicity excluded from this warranty are: special finishes and labor required to remove and/or reinstall original or replacement parts.

This warranty does not cover damage caused by improper installation, overloading, accident, improper storage, alternations, modifications, or additions.

USED METAL LOCKERS ARE DEVOID OF WARRANTY AND SOLD STRICTLY IN “AS-IS” CONDITION.

Lightning Lockers warrants the items purchased from other manufacturers only to the extent of the normal warranty of these manufacturers.

The above warranties are given in lieu or all other warranties express or implied, including without limitation, the warranty of merchantability and the warranty of suitability for a particular purpose. It is expressly agreed that Lightning Lockers assumes no liability for liquidated damages arising out of a breech of contract, including any warranties arising therefrom, and buyer’s remedy shall be limited to repair or replacement of defective parts as described above.

Online orders are subject to review prior to acceptance and processing. Freight calculations resulting from online orders will be processed at face value. If the calculated freight is deemed insufficient (i.e. residential delivery, extreme locations), the customer will be promptly notified with a revised freight charge prior to the acceptance of any funds by Lightning Lockers. A faxed copy of a revised freight form will be supplied for the customer’s approval and signature prior to any additional action by Lightning Lockers.

OVERSIZED UNITS

18″ Wide metal lockers may be assembled less than 3-Wide to aid in shipment and customer handling and receiving.

QUOTATIONS

Prices quoted are subject to receipt and acceptance of order within 30 days of the date of the quotation unless otherwise noted on quote.

TAXES

Lightning Lockers reserves the right to add sales tax, or any other tax, which may be imposed on our products, as requited by law. All shipments into the State of Ohio will carry the current state sales tax unless a resale certificate for the State of Ohio is on file at Lightning Lockers.

TERMS OF PAYMENT

Payment terms are available to existing customers. New customer must furnish prepayment via credit card or check. COD payment is available at the cost of carrier surcharge.

CANCELLATIONS

Written consent from Lightning Lockers must be obtained prior to the cancellation of any order. Cancellation charges may apply.

RETURNED GOODS

Prior written authorization from Lightning Lockers must be obtained before credit on returned goods will be given. Returns shall be subject to a 30% restocking charge and must be returned to Lightning Lockers freight “prepaid”.

Used metal lockers are non-returnable.

LOSS IN TRANSIT

Lightning Lockers shall not be liable for loss or damage in transit.

Products received freight prepaid must be checked against the packing list to ensure all items were delivered. In case of shortages, not on the carrier’s paperwork “Shipment Received Short”. If shortage is not discovered upon receipt from carrier, Lightning Lockers must be notified of shortages within 24 hours or receipt to ensure a claim for loss can be filed. Shortages reported later than 24 hours carry no guarantee of replacement/credit.

DELIVERIES

Delivery dates are estimated dates only, and unless otherwise specified, are estimated from the date of receipt by Lightning Lockers of purchase order, complete technical data and approved drawings. In estimating such dates, no allowance will be made, nor shall we be liable directly or indirectly, for delays or carriers or delays from labor difficulties, shortages, strikes or stoppages of any sort, fires, accidents, failure or delay in obtaining materials or manufacturing facilities, acts of government affecting us directly or indirectly, bad weather or any causes beyond our control or causes designated as Acts of God or forces of nature by any court of law, and the estimated delivery dates shall be extended accordingly. We will not be liable for any damages or penalties, whatsoever, whether direct, indirect, special or consequential, resulting from our failure to perform or delay in performing unless otherwise agreed in writing by an authorized officer of Lightning Lockers.

FOR SPECIAL DESIGNS AND/OR APPLICATIONS NOT SHOWN ON OUR WEBSITE, PLEASE CONSULT LIGHTNING LOCKERS BY CALLING 1-800-497-6895.

[/et_pb_text][/et_pb_column][/et_pb_row][et_pb_row _builder_version=”3.1.1″][et_pb_column type=”1_4″][et_pb_blurb _builder_version=”3.1.1″ url=”http://www.lightninglockers.com/product-category/default-category/shop/new/” image=”http://www.lightninglockers.com/wp-content/uploads/2018/05/new_loc.png” animation=”off” /][/et_pb_column][et_pb_column type=”1_4″][et_pb_blurb _builder_version=”3.1.1″ url=”http://www.lightninglockers.com/product-category/default-category/shop/used/” image=”http://www.lightninglockers.com/wp-content/uploads/2018/05/used_loc.png” animation=”off” /][/et_pb_column][et_pb_column type=”1_4″][et_pb_blurb _builder_version=”3.1.1″ url=”http://www.lightninglockers.com/product-category/default-category/shop/locker-benches/” image=”http://www.lightninglockers.com/wp-content/uploads/2018/05/loc_ben.png” animation=”off” /][/et_pb_column][et_pb_column type=”1_4″][et_pb_blurb _builder_version=”3.1.1″ url=”http://www.lightninglockers.com/product-category/default-category/shop/locker-accessories/” image=”http://www.lightninglockers.com/wp-content/uploads/2018/05/loc_acc.png” animation=”off” /][/et_pb_column][/et_pb_row][/et_pb_section][et_pb_section bb_built=”1″ specialty=”off” _builder_version=”3.1.1″ custom_margin=”-30px|||” custom_padding=”0px|||” global_module=”1597″ prev_background_color=”#000000″][et_pb_row global_parent=”1597″ background_position=”top_left” background_repeat=”repeat” background_size=”initial” _builder_version=”3.1.1″ custom_margin=”0px|||” custom_padding=”0px|||” padding_top_1=”0px” padding_top_2=”0px” padding_top_3=”0px”][et_pb_column type=”1_3″][et_pb_button global_parent=”1597″ _builder_version=”3.1.1″ button_text=”Locker Gallery” button_url=”http://www.lightninglockers.com/gallery/” button_alignment=”left” custom_button=”on” button_text_size=”15″ button_text_color=”#000000″ button_bg_color=”#edf000″ button_border_color=”#edf000″ button_icon_color=”#595959″ button_on_hover=”off” /][et_pb_button global_parent=”1597″ _builder_version=”3.1.1″ button_text=”FAQs” button_url=”http://www.lightninglockers.com/faqs/” button_alignment=”left” custom_button=”on” button_text_size=”15″ button_text_color=”#000000″ button_bg_color=”#edf000″ button_border_color=”#edf000″ button_icon_color=”#595959″ button_on_hover=”off” /][/et_pb_column][et_pb_column type=”1_3″][et_pb_button global_parent=”1597″ _builder_version=”3.1.1″ button_text=”We Buy Used Lockers!” button_url=”http://www.lightninglockers.com/we-buy-used-lockers/” button_alignment=”left” custom_button=”on” button_text_size=”15″ button_text_color=”#000000″ button_bg_color=”#edf000″ button_border_color=”#edf000″ button_icon_color=”#595959″ button_on_hover=”off” /][et_pb_button global_parent=”1597″ _builder_version=”3.1.1″ button_text=”Request a Quote” button_url=”http://www.lightninglockers.com/request-a-quote/” button_alignment=”left” custom_button=”on” button_text_size=”15″ button_text_color=”#000000″ button_bg_color=”#edf000″ button_border_color=”#edf000″ button_icon_color=”#595959″ button_on_hover=”off” /][/et_pb_column][et_pb_column type=”1_3″][et_pb_button global_parent=”1597″ _builder_version=”3.1.1″ button_text=”Color Chart” button_url=”http://www.lightninglockers.com/color-chart/” button_alignment=”left” custom_button=”on” button_text_size=”15″ button_text_color=”#000000″ button_bg_color=”#edf000″ button_border_color=”#edf000″ button_icon_color=”#595959″ button_on_hover=”off” /][/et_pb_column][/et_pb_row][/et_pb_section]